At HGAD, we are dedicated to creating outstanding architectural designs that inspire, captivate, and transform spaces. Our mission is to bring your vision to life through innovative and sustainable design solutions. By accessing our website and using our services, you agree to the following terms and conditions:
-
Design Services
1.1 We offer a range of architectural design services, including conceptual design, 3D visualization, interior design, and project management. Our team of skilled architects and designers will work closely with you to understand your requirements and deliver designs that exceed your expectations.
1.2 All design services provided by HGAD are subject to the specific terms and conditions agreed upon in the project contract or agreement.
-
Intellectual Property
2.1 HGAD retains all intellectual property rights to the architectural designs created by our team, including drawings, renderings, and specifications. These designs are protected by copyright and other applicable laws.
2.2 Upon completion of the project and full payment of our fees, HGAD may grant you a license to use the architectural designs for the specified project. This license is non-exclusive and non-transferable, and its terms will be outlined in the project contract or agreement.
2.3 You agree not to reproduce, modify, distribute, or use the architectural designs created by HGAD for any purpose beyond the scope of the agreed-upon project without our explicit written consent.
-
Client Responsibilities
3.1 As our client, you are responsible for providing accurate and complete information regarding your project requirements, goals, and constraints. This includes providing necessary site information, project specifications, and any applicable legal or regulatory requirements.
3.2 You acknowledge that any delays or changes in the project timeline or scope resulting from incomplete or inaccurate information provided by you may have an impact on the project schedule and budget. HGAD will make reasonable efforts to accommodate such changes, but additional fees and timeline adjustments may apply.
-
Payments and Fees
4.1 The fees for our architectural design services will be outlined in the project contract or agreement. Payment terms, including the schedule and method of payment, will also be specified in the agreement.
4.2 Unless otherwise stated, all fees quoted by HGAD are exclusive of applicable taxes, which will be added to the final invoice.
4.3 In the event of any additional services or changes to the project scope requested by you, HGAD reserves the right to adjust the fees and timeline accordingly. Any changes to the project scope will be documented in writing and agreed upon by both parties.
-
Confidentiality
5.1 HGAD acknowledges the confidential nature of the information shared by you during the course of the project. We will take reasonable measures to maintain the confidentiality of such information, except where disclosure is required by law or where necessary for the proper execution of the project.
-
Limitation of Liability
6.1 While HGAD strives to deliver high-quality architectural designs, we cannot guarantee the suitability, accuracy, or completeness of the designs for your specific project. We shall not be liable for any direct, indirect, incidental, consequential, or special damages arising from your use or reliance on our designs or services.
6.2 You agree to indemnify and hold HGAD and its employees harmless from any claims, damages, losses, or expenses arising out of or related to your use of our designs or services.
-
Governing Law
7.1 These terms and conditions shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes or claims arising out of or in connection with these terms shall be subject to the exclusive jurisdiction of the courts of [Jurisdiction].
Thank you for choosing HGAD as your architectural design partner. We look forward to working with you to create